United Granite NJ

Effective Date: March 30, 2026

Welcome to United Granite NJ. These Terms and Conditions (“Terms”) govern your access to and use of our website, products, and services. By accessing or using this Website, you agree to comply with and be legally bound by these Terms. If you do not agree with any part of these Terms, please do not use our Website.

Throughout these Terms, “United Granite NJ,” “Company,” “we,” “our,” or “us” refers to United Granite NJ, and “you” or “user” refers to any visitor, customer, or person accessing the Website.

1. Website Use

The content on this Website is provided for general informational and commercial purposes related to our granite, quartz, marble, fabrication, installation, remodeling, and related services.

By using this Website, you agree that you will:

• Use the Website only for lawful purposes

• Not attempt to interfere with the security or operation of the Website

• Not copy, reproduce, distribute, or exploit Website content without written permission

• Not use the Website in any way that could damage, disable, or impair our services or reputation

We reserve the right to suspend or terminate access to the Website at our sole discretion if these Terms are violated.

2. Services and Estimates

United Granite NJ provides stone fabrication, countertop installation, remodeling consultation, and related services. Any project estimates, quotes, pricing, timelines, or service descriptions provided through the Website, email, phone, or consultations are subject to change based on measurements, material availability, project scope, and site conditions.

All estimates are non-binding until confirmed through a signed agreement or approved invoice.

We reserve the right to refuse service, cancel orders, or modify service offerings at any time without prior notice.

3. Product and Material Information

We make reasonable efforts to ensure that all descriptions, colors, images, dimensions, and specifications displayed on the Website are accurate. However, natural stone products including granite, marble, and quartz may vary in color, texture, veining, and appearance.

Because natural materials are unique, final products may differ slightly from photographs, samples, or digital previews shown on the Website or during consultations.

United Granite NJ does not guarantee exact matches between displayed samples and delivered materials.

4. Payments and Pricing

All pricing displayed on the Website or provided through estimates is subject to change without notice.

Payment terms for projects, fabrication, delivery, and installation services will be outlined in invoices, contracts, or service agreements provided to the customer. Failure to make payments on time may result in project delays, cancellation of services, or additional fees where permitted by law.

Customers are responsible for providing accurate billing information.

5. Scheduling, Delivery, and Installation

Installation dates, delivery timelines, and project completion estimates are approximate and may be affected by material availability, weather conditions, supplier delays, site readiness, labor availability, or unforeseen circumstances.

United Granite NJ shall not be held liable for delays outside of our reasonable control.

Customers are responsible for ensuring that job sites are properly prepared and accessible before scheduled installation or delivery dates.

6. Intellectual Property Rights

All content on this Website, including but not limited to text, logos, branding, graphics, designs, images, layouts, icons, videos, and software, is the property of United Granite NJ or its licensors and is protected under applicable intellectual property and copyright laws.

You may not reproduce, distribute, modify, publish, transmit, or create derivative works from any Website content without prior written consent from United Granite NJ.

7. Third-Party Links

This Website may contain links to third-party websites or services for convenience and informational purposes. United Granite NJ does not control or endorse third-party websites and is not responsible for their content, privacy policies, practices, or availability.

Accessing third-party websites is done at your own risk.

8. Disclaimer of Warranties

This Website and all content, materials, and services provided through it are offered on an “as is” and “as available” basis without warranties of any kind, whether express or implied.

To the fullest extent permitted by law, United Granite NJ disclaims all warranties, including but not limited to:

• Merchantability

• Fitness for a particular purpose

• Non-infringement

• Accuracy or reliability of Website content

• Continuous or error-free Website operation

We do not guarantee that the Website will always be secure, uninterrupted, or free from viruses or harmful components.

9. Limitation of Liability

To the maximum extent permitted by law, United Granite NJ shall not be liable for any indirect, incidental, consequential, special, punitive, or exemplary damages arising from:

• Your use or inability to use the Website

• Errors or inaccuracies on the Website

• Delays or interruptions in Website availability

• Loss of business, revenue, profits, or data

• Third-party conduct or services

Our total liability for any claim related to the Website or services shall not exceed the amount paid by the customer for the applicable service giving rise to the claim.

10. Indemnification

You agree to defend, indemnify, and hold harmless United Granite NJ, its owners, employees, contractors, affiliates, and representatives from and against any claims, liabilities, damages, losses, costs, or expenses arising from:

• Your use of the Website

• Your violation of these Terms

• Your infringement of any rights of another person or entity

11. Privacy and Cookies

Your use of the Website is also governed by our Privacy Policy and Cookie Policy. By using the Website, you consent to the collection and use of information in accordance with those policies.

12. Cookie Policy

What Are Cookies?

Cookies are small text files stored on your device when you visit a website. They help websites function efficiently, improve user experience, remember preferences, and provide analytical information regarding website usage.

How We Use Cookies

United Granite NJ uses cookies and similar technologies to:

• Ensure proper Website functionality

• Improve user experience and Website performance

• Analyze visitor traffic and Website interactions

• Remember user preferences and settings

• Enhance security and fraud prevention

Types of Cookies We Use

Essential Cookies

These cookies are necessary for the operation and security of the Website. Without them, certain Website features may not function properly.

Performance and Analytics Cookies

These cookies collect anonymous information about how visitors use our Website, including page visits, traffic sources, and user behavior, helping us improve Website performance and services.

Functionality Cookies

These cookies allow the Website to remember your preferences and settings to provide a more personalized browsing experience.

Third-Party Cookies

We may use trusted third-party services such as analytics providers, embedded content providers, or marketing tools that place cookies on your device in accordance with their own privacy policies.

Managing Cookies

You may control or disable cookies through your browser settings. Most browsers allow you to:

• Delete stored cookies

• Block cookies entirely

• Receive notifications when cookies are being used

Please note that disabling cookies may affect the functionality and performance of certain areas of the Website.

Consent to Cookies

By continuing to use our Website, you consent to the use of cookies as described in this Cookie Policy. Where required by applicable law, we may request your explicit consent before placing non-essential cookies on your device.

Changes to This Cookie Policy

United Granite NJ reserves the right to modify or update this Cookie Policy at any time. Updates will become effective immediately upon posting to this page unless otherwise stated.

13. Governing Law

These Terms shall be governed and interpreted in accordance with the laws of the State of New Jersey, without regard to conflict of law principles.

Any disputes arising out of or relating to these Terms or the use of the Website shall be subject to the exclusive jurisdiction of the courts located in New Jersey, United States.

14. Changes to These Terms

We reserve the right to update, modify, or replace these Terms at any time without prior notice. Continued use of the Website after changes are posted constitutes acceptance of the revised Terms.

We encourage users to review these Terms periodically.

15. Contact Information

If you have any questions regarding these Terms and Conditions or Cookie Policy, please contact us:

United Granite NJ

unitedgranitenj.com
Email: info@unitedgranitenj.com
Phone: (908) 231-6677

This document is provided for general informational purposes and should not be considered legal advice. United Granite NJ recommends consulting a qualified attorney to ensure full compliance with all applicable laws and regulations.